T&Cs for the supply of Goods and Services – Parker Electrical Environmental Limited trading as PEEL Pumps
The Customer’s attention is particularly drawn to the provisions of clause 13 (Limitation of liability).
The following definitions and rules of interpretation apply in this agreement.
Business Day: a day other than a Saturday, Sunday or public holiday in England, when banks in London are open for business.
Commencement Date: has the meaning given in clause 2.2.
Conditions: these terms and conditions as amended from time to time in accordance with clause 17.8.
Contract: the contract between the Supplier and the Customer for the supply of Goods and/or Services in accordance with these Conditions.
Customer: the person or firm who purchases the Goods and/or Services from the Supplier.
Data Subject: an individual who is the subject of Personal Data.
Delivery Location: has the meaning given in clause 4.1.
Force Majeure Event: has the meaning given to it in clause 16.
Goods: the goods or any part of them) as set out in the Quotation.
Intellectual Property Rights: patents, rights to inventions, copyright and related rights, moral rights, trade marks, business names and domain names, rights in get-up and trade dress, goodwill and the right to sue for passing off or unfair competition, rights in designs, rights in computer software, database rights, rights to use, and protect the confidentiality of, confidential information (including know-how and trade secrets), and all other intellectual property rights, in each case whether registered or unregistered and including all applications and rights to apply for and be granted, renewals or extensions of, and rights to claim priority from, such rights and all similar or equivalent rights or forms of protection which subsist or will subsist now or in the future in any part of the world.
Quotation: the Supplier’s quotation for the supply of Goods and/or Services.
Personal Data: has the meaning set out in section 1(1) of the Data Protection Act 1998 and relates only to personal data, or any part of such personal data, in respect of which the Customer is the Data Controller and in relation to which the Supplier is providing services under the Contract.
Processing and process: have the meaning set out in section 1(1) of the Data Protection Act 1998.
Services: the services supplied by the Supplier to the Customer as set out in the Service Specification.
Service Specification: the description or specification for the Services provided in the Quotation or in writing by the Supplier to the Customer.
Supplier: PE Environmental Limited t/a Peel Pumps registered in England and Wales with company number 07127777 whose registered office is at 62 Woodhey Road, Ramsbottom BL0 9RB.
Supplier Materials: has the meaning given in clause 8.1(f).
2. Basis of contract
2.1 Acceptance of the Quotation constitutes an offer by the Customer to purchase Goods and/or Services in accordance with these Conditions.
2.2 The Customer’s offer shall only be deemed to be accepted when the Supplier issues written acceptance of the offer at which point and on which date the Contract shall come into existence (Commencement Date).
2.3 Any samples, drawings, descriptive matter or advertising issued by the Supplier and any descriptions of the Goods or illustrations or descriptions of the Services contained in the Supplier’s catalogues or brochures or on the Supplier’s website or portal are issued or published for the sole purpose of giving an approximate idea of the Services and/or Goods described in them. They shall not form part of the Contract or have any contractual force.
2.4 These Conditions apply to the Contract to the exclusion of any other terms that the Customer seeks to impose or incorporate, or which are implied by trade, custom, practice or course of dealing.
3.1 The Goods are described in the Goods Specification.
3.2 The Supplier reserves the right to amend the Goods Specification if required by any applicable statutory or regulatory requirement, and the Supplier shall notify the Customer in any such event.
4. Delivery of Goods
4.1 The Supplier shall deliver the Goods to the location set out in the Quotation or such other location as the parties may agree (Delivery Location) at any time after the Supplier notifies the Customer that the Goods are ready.
4.2 Delivery of the Goods shall be completed on the unloading of the Goods at the Delivery Location.
4.3 Any dates quoted for delivery of the Goods are approximate only, and the time of delivery is not of the essence. The Supplier shall not be liable for any delay in delivery of the Goods that is caused by a Force Majeure Event or the Customer’s failure to provide the Supplier with adequate delivery instructions or any other instructions that are relevant to the supply of the Goods.
4.4 If the Supplier fails to deliver the Goods, its liability shall be limited to the costs and expenses incurred by the Customer in obtaining replacement goods of similar description and quality in the cheapest market available, less the price of the Goods. The Supplier shall have no liability for any failure to deliver the Goods to the extent that such failure is caused by a Force Majeure Event or the Customer’s failure to provide the Supplier with adequate delivery instructions for the Goods or any relevant instruction related to the supply of the Goods.
5.1 The Supplier warrants that on delivery, and for a period of 12 months from the date of delivery (warranty period), the Goods shall:
(a) conform in all material respects with their description;
(b) be free from material defects in design, material and workmanship; and
(c) be of satisfactory quality (within the meaning of the Sale of Goods Act 1979).
5.2 Subject to clause 5.3, the Supplier shall, at its option, repair or replace the defective Goods, or refund the price of the defective Goods in full if:
(a) the Customer gives notice in writing during the warranty period within a reasonable time of discovery that some or all of the Goods do not comply with the warranty set out in clause 5.1;
(b) the Supplier is given a reasonable opportunity of examining such Goods; and
(c) the Customer (if asked to do so by the Supplier) returns such Goods to the Supplier’s place of business at the Customer’s cost.
5.3 The Supplier shall not be liable for the Goods’ failure to comply with the warranty in clause 5.1 if:
(a) the Customer makes any further use of such Goods after giving a notice in accordance with clause 5.2;
(b) the defect arises because the Customer failed to follow the Supplier’s oral or written instructions as to the storage, installation, commissioning, use or maintenance of the Goods or (if there are none) good trade practice;
(c) the Customer alters or repairs such Goods without the written consent of the Supplier;
(d) the defect arises as a result of fair wear and tear, wilful damage, negligence, or abnormal working conditions.
5.5 The terms of these Conditions shall apply to any repaired or replacement Goods supplied by the Supplier.
6. Title and risk
6.1 The risk in the Goods shall pass to the Customer on completion of delivery.
6.2 Title to the Goods shall not pass to the Customer until the Supplier receives payment in full (in cash or cleared funds) for the Goods.
7. Supply of Services
7.1 The Supplier shall supply the Services to the Customer in accordance with the Service Specification in all material respects.
7.2 The Supplier shall use all reasonable endeavours to meet any performance dates for the Services specified on the Quotation, but any such dates shall be estimates only and time shall not be of the essence for the performance of the Services.
7.3 The Supplier reserves the right to amend the Service Specification if necessary to comply with any applicable law or regulatory requirement, or if the amendment will not materially affect the nature or quality of the Services, and the Supplier shall notify the Customer in any such event.
7.4 The Supplier warrants to the Customer that the Services will be provided using reasonable care and skill.
8. Customer’s obligations
8.1 The Customer shall:
(a) ensure that the terms of the Quotation are complete and accurate;
(b) co-operate with the Supplier in all matters relating to the Services;
(c) provide the Supplier, its employees, agents, consultants and subcontractors, with access to the Customer’s premises, office accommodation and other facilities as reasonably required by the Supplier to provide the Services;
(d) provide the Supplier with such information and materials as the Supplier may reasonably require in order to supply the Services, and ensure that such information is complete and accurate in all material respects;
(e) comply with all applicable laws, including health and safety laws;
(f) keep all materials, equipment, documents and other property of the Supplier (Supplier Materials) at the Customer’s premises in safe custody at its own risk, maintain the Supplier Materials in good condition until returned to the Supplier, and not dispose of or use the Supplier Materials other than in accordance with the Supplier’s written instructions or authorisation;
(g) comply with any additional obligations as set out in the Service Specification and the Goods Specification; and
(h) ensure that, if required, the Goods are correctly installed and are connected to a power source and the internet at all times.
8.2 If the Supplier’s performance of any of its obligations under the Contract is prevented or delayed by any act or omission by the Customer or failure by the Customer to perform any relevant obligation, (Customer Default):
(a) without limiting or affecting any other right or remedy available to it, the Supplier shall have the right to suspend performance of the Services until the Customer remedies the Customer Default, and to rely on the Customer Default to relieve it from the performance of any of its obligations in each case to the extent the Customer Default prevents or delays the Supplier’s performance of any of its obligations;
(b) the Supplier shall not be liable for any costs or losses sustained or incurred by the Customer arising directly or indirectly from the Supplier’s failure or delay to perform any of its obligations as set out in this clause 8.2; and
(c) the Customer shall reimburse the Supplier on written demand for any costs or losses sustained or incurred by the Supplier arising directly or indirectly from the Customer Default.
9. Charges and payment
9.1 The price for Goods:
(a) shall be the price set out in the Quotation; and
(b) shall be exclusive of all costs and charges of packaging, insurance, transport and installation of the Goods, which shall be invoiced to the Customer.
9.2 The charges for Services shall be calculated as set out in the Quotation:
(a) Installation charges (if any) and the first year’s monitoring charge will be invoiced on or around the Commencement Date;
(b) Subsequent monitoring charges will be invoiced on each anniversary of the Commencement Date;
(c) Any additional Services, including but not limited to repairs, maintenance and modification of the Goods, will be charged in accordance with the Quotation provided to the Customer at the time;
(d) the Supplier shall be entitled to charge the Customer for any expenses reasonably incurred by the individuals whom the Supplier engages in connection with the Services including travelling expenses, hotel costs, subsistence and any associated expenses, and for the cost of services provided by third parties and required by the Supplier for the performance of the Services, and for the cost of any materials.
9.3 The Supplier reserves the right to:
(a) increase the charges for the Services on an annual basis with effect from each anniversary of the Commencement Date in line with the percentage increase in the Retail Prices Index in the preceding 12-month period and the first such increase shall take effect on the first anniversary of the Commencement Date and shall be based on the latest available figure for the percentage increase in the Retail Prices Index;
(b) increase the price of the Goods, by giving notice to the Customer at any time before delivery, to reflect any increase in the cost of the Goods to the Supplier that is due to:
(i) any factor beyond the control of the Supplier (including foreign exchange fluctuations, increases in taxes and duties, and increases in labour, materials and other manufacturing costs);
(ii) any request by the Customer to change the delivery date(s), quantities or types of Goods ordered, or the Goods Specification; or
(iii) any delay caused by any instructions of the Customer in respect of the Goods or failure of the Customer to give the Supplier adequate or accurate information or instructions in respect of the Goods.
9.4 In respect of Goods, the Supplier shall invoice the Customer on or at any time after completion of delivery. In respect of Services, the Supplier shall invoice the Customer when the Services are completed or annually in respect of the ongoing monitoring charges, as indicated on the Quotation.
9.5 The Customer shall pay each invoice submitted by the Supplier within 30 days of the date of the invoice in full and in cleared funds to a bank account nominated in writing by the Supplier, and time for payment shall be of the essence of the Contract.
9.6 If the Customer fails to make a payment due to the Supplier under the Contract by the due date, then, without limiting the Supplier’s remedies under clause 14 (Termination), the Customer shall pay interest on the overdue sum from the due date until payment of the overdue sum, whether before or after judgment. Interest under this clause 9.6 will accrue each day at 4% a year above the Bank of England’s base rate from time to time, but at 4% a year for any period when that base rate is below 0%.
9.7 All amounts due under the Contract shall be paid in full without any set-off, counterclaim, deduction or withholding (other than any deduction or withholding of tax as required by law).
10. Intellectual property rights
10.1 All Intellectual Property Rights in or arising out of or in connection with the Goods and Services (other than Intellectual Property Rights in any materials provided by the Customer) shall be owned by (under licence or otherwise) the Supplier.
10.2 The Customer grants the Supplier a fully paid-up, non-exclusive, royalty-free non-transferable licence to copy and modify any materials provided by the Customer to the Supplier for the term of the Contract for the purpose of providing the Services to the Customer.
11. Data protection and data processing
11.1 The Supplier shall process the Personal Data only in accordance with the Customer’s instructions from time to time and shall not process the Personal Data for any purposes other than those expressly authorised by the Customer.
11.2 Each party warrants to the other that it will process the Personal Data in compliance with all applicable laws, enactments, regulations, orders, standards and other similar instruments.
11.3 The Customer acknowledges that the Supplier is reliant on the Customer for direction as to the extent to which the Supplier is entitled to use and process the Personal Data. Consequently, the Supplier will not be liable for any claim brought by a Data Subject arising from any action or omission by the Supplier, to the extent that such action or omission resulted directly from the Customer’s instructions.
11.4 The Supplier may authorise a third party (subcontractor) to process the Personal Data provided that the subcontractor’s contract:
(a) is on terms which are substantially the same as those set out in this agreement; and
(b) terminates automatically on termination of this agreement for any reason.
12.1 Each party undertakes that it shall not at any time disclose to any person any confidential information concerning the business, affairs, customers, clients or suppliers of the other party, except as permitted by clause 12.2.
12.2 Each party may disclose the other party’s confidential information:
(a) to its employees, officers, representatives, subcontractors or advisers who need to know such information for the purposes of carrying out the party’s obligations under the Contract. Each party shall ensure that its employees, officers, representatives, subcontractors or advisers to whom it discloses the other party’s confidential information comply with this clause 12; and
(b) as may be required by law, a court of competent jurisdiction or any governmental or regulatory authority.
12.3 Neither party shall use the other party’s confidential information for any purpose other than to perform its obligations under the Contract.
13.1 Nothing in these Conditions shall limit or exclude the Supplier’s liability for:
(a) death or personal injury caused by its negligence, or the negligence of its employees, agents or subcontractors;
(b) fraud or fraudulent misrepresentation;
(c) breach of the terms implied by section 2 of the Supply of Goods and Services Act 1982 (title and quiet possession);breach of the terms implied by section 12 of the Sale of Goods Act 1979 (title and quiet possession); or
(d) defective products under the Consumer Protection Act 1987.
13.2 Subject to clause 13.1, the Supplier shall not be liable to the Customer, whether in contract, tort (including negligence), for breach of statutory duty, or otherwise, arising under or in connection with the Contract for:
(a) loss of profits;
(b) loss of sales or business;
(c) loss of agreements or contracts;
(d) loss of anticipated savings;
(e) loss of use or corruption of software, data or information;
(f) loss of or damage to goodwill; or
(g) any indirect or consequential loss.
13.3 Subject to clause 13.1, the Supplier’s total liability to the Customer, whether in contract, tort (including negligence), breach of statutory duty or otherwise, arising under or in connection with the Contract, shall be limited to an amount equivalent to the total charges paid under the Contract during the 12 months immediately prior.
13.4 The terms implied by sections 13 to 15 of the Sale of Goods Act 1979 and the terms implied by sections 3 to 5 of the Supply of Goods and Services Act 1982 are, to the fullest extent permitted by law, excluded from the Contract.
13.5 This clause 13 shall survive termination of the Contract.
14.1 Without affecting any other right or remedy available to it, either party may terminate the Contract by giving the other party not less than six months’ written notice.
14.2 Without affecting any other right or remedy available to it, either party may terminate the Contract with immediate effect by giving written notice to the other party if:
(a) the other party commits a material breach of its obligations under the Contract and (if such breach is remediable) fails to remedy that breach within 30 days after receipt of notice in writing to do so;
(b) the other party takes any step or action in connection with its entering administration, provisional liquidation or any composition or arrangement with its creditors (other than in relation to a solvent restructuring), being wound up (whether voluntarily or by order of the court, unless for the purpose of a solvent restructuring), having a receiver appointed to any of its assets or ceasing to carry on business;
(c) the other party suspends, or threatens to suspend, or ceases or threatens to cease to carry on all or a substantial part of its business; or
(d) the other party’s financial position deteriorates to such an extent that in the terminating party’s opinion the other party’s capability to adequately fulfil its obligations under the Contract has been placed in jeopardy.
14.3 Without affecting any other right or remedy available to it, the Supplier may terminate the Contract with immediate effect by giving written notice to the Customer if the Customer fails to pay any amount due under the Contract on the due date for payment.
14.4 Without affecting any other right or remedy available to it, the Supplier may suspend the supply of Services or all further deliveries of Goods under the Contract or any other contract between the Customer and the Supplier if the Customer fails to pay any amount due under the Contract on the due date for payment, the Customer becomes subject to any of the events listed in clause 14.2(b) to clause 14.2(d), or the Supplier reasonably believes that the Customer is about to become subject to any of them.
15. Consequences of termination
15.1 On termination of the Contract:
(a) the Customer shall immediately pay to the Supplier all of the Supplier’s outstanding unpaid invoices and interest and, in respect of Services and Goods supplied but for which no invoice has been submitted, the Supplier shall submit an invoice, which shall be payable by the Customer immediately on receipt;
(b) the Customer shall return all of the Supplier Materials or Goods which have not been fully paid for. If the Customer fails to do so, then the Supplier may enter the Customer’s premises and take possession of them. Until they have been returned, the Customer shall be solely responsible for their safe keeping and will not use them for any purpose not connected with this Contract.
15.2 Termination of the Contract shall not affect any rights, remedies, obligations and liabilities of the parties that have accrued up to the date of termination, including the right to claim damages in respect of any breach of the Contract which existed at or before the date of termination.
15.3 Any provision of the Contract that expressly or by implication is intended to have effect after termination shall continue in full force and effect.
Neither party shall be in breach of the Contract nor liable for delay in performing or failure to perform, any of its obligations under the Contract if such delay or failure result from events, circumstances or causes beyond its reasonable control.
17.1 Assignment and other dealings
(a) The Supplier may at any time assign, mortgage, charge, subcontract, delegate, declare a trust over or deal in any other manner with any or all of its rights and obligations under the Contract.
(b) The Customer shall not assign, transfer, mortgage, charge, subcontract, declare a trust over or deal in any other manner with any of its rights and obligations under the Contract without the prior written consent of the Supplier.
(a) Any notice or other communication given to a party under or in connection with the Contract shall be in writing and shall be delivered by hand or by pre-paid first-class post or other next working day delivery service at its registered office (if a company).
(b) Any notice or other communication shall be deemed to have been received: if delivered by hand, on signature of a delivery receipt or at the time the notice is left at the proper address; if sent by pre-paid first-class post or other next working day delivery service, at 9.00 am on the Business Day after posting or at the time recorded by the delivery service.
(c) This clause does not apply to the service of any proceedings or other documents in any legal action or, where applicable, any other method of dispute resolution.
17.3 Severance. If any provision or part-provision of the Contract is or becomes invalid, illegal or unenforceable, it shall be deemed modified to the minimum extent necessary to make it valid, legal and enforceable. If such modification is not possible, the relevant provision or part- provision shall be deemed deleted. Any modification to or deletion of a provision or part- provision under this clause shall not affect the validity and enforceability of the rest of the Contract.
17.4 Waiver. A waiver of any right or remedy under the Contract or by law is only effective if given in writing and shall not be deemed a waiver of any subsequent breach or default. A failure or delay by a party to exercise any right or remedy provided under the Contract or by law shall not constitute a waiver of that or any other right or remedy, nor shall it prevent or restrict any further exercise of that or any other right or remedy. No single or partial exercise of any right or remedy provided under the Contract or by law shall prevent or restrict the further exercise of that or any other right or remedy.
17.5 No partnership or agency. Nothing in the Contract is intended to, or shall be deemed to, establish any partnership or joint venture between the parties, constitute either party the agent of the other, or authorise either party to make or enter into any commitments for or on behalf of the other party.
17.6 Entire agreement.
(a) The Contract constitutes the entire agreement between the parties and supersedes and extinguishes all previous agreements, promises, assurances, warranties, representations and understandings between them, whether written or oral, relating to its subject matter.
(b) Each party acknowledges that in entering into the Contract it does not rely on, and shall have no remedies in respect of any statement, representation, assurance or warranty (whether made innocently or negligently) that is not set out in the Contract.
Each party agrees that it shall have no claim for innocent or negligent misrepresentation based on any statement in the Contract.
(c) Nothing in this clause shall limit or exclude any liability for fraud.
17.7 Third parties rights. The Contract does not give rise to any rights under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of the Contract.
17.8 Variation. Except as set out in these Conditions, no variation of the Contract shall be effective unless it is agreed in writing and signed by the parties (or their authorised representatives).
17.9 Governing law. The Contract and any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with it or its subject matter or formation shall be governed by and construed in accordance with the law of England and Wales.
17.10 Jurisdiction. Each party irrevocably agrees that the courts of England and Wales shall have exclusive jurisdiction to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.